(2) A person bringing an action under this section must establish a violation of ORS 279C.840, 316.167, 656.017, 657.505, 701.021 or 701.026 by a preponderance of the evidence.
(3) Upon establishing that the violation occurred, the person shall recover, as liquidated damages, 10 percent of the total amount of the contract or $5,000, whichever is greater.
(4) In any action under this section, the prevailing party is entitled to an award of reasonable attorney fees.
(5) An action under this section must be commenced within two years of the substantial completion of the construction, repair, remodeling, alteration, conversion, modernization, improvement, rehabilitation, replacement or renovation. For the purposes of this subsection, "substantial completion" has the meaning given that term in ORS 12.135.
(6) A person may not recover any amounts under this section if the defendant in the action establishes by a preponderance of the evidence that the plaintiff:
(a) Was in violation of ORS 701.021 or 701.026 at the time of making the bid or proposal on the contract;
(b) Was in violation of ORS 316.167, 656.017 or 657.505 with respect to any employees of the plaintiff as of the time of making the bid or proposal on the contract; or
(c) Was in violation of ORS 279C.840 with respect to any contract performed by the plaintiff within one year before making the bid or proposal on the contract at issue in the action. [2003 c.794 §135; 2007 c.836 §44]
Copyright ©2024 LegalFix. All rights reserved. LegalFix is not a law firm, is not licensed to practice law, and does not provide legal advice, services, or representation. The information on this website is an overview of the legal plans you can purchase—or that may be provided by your employer as an employee benefit or by your credit union or other membership group as a membership benefit.
LegalFix provides its members with easy access to affordable legal services through a network of independent law firms. LegalFix, its corporate entity, and its officers, directors, employees, agents, and contractors do not provide legal advice, services, or representation—directly or indirectly.
The articles and information on the site are not legal advice and should not be relied upon—they are for information purposes only. You should become a LegalFix member to get legal services from one of our network law firms.
You should not disclose confidential or potentially incriminating information to LegalFix—you should only communicate such information to your network law firm.
The benefits and legal services described in the LegalFix legal plans are not always available in all states or with all plans. See the legal plan Benefit Overview and the more comprehensive legal plan contract during checkout for coverage details in your state.
Use of this website, the purchase of legal plans, and access to the LegalFix networks of law firms are subject to the LegalFix Terms of Service and Privacy Policy.