Subdivision 1. Dismissal. (a) A proceeding under this chapter may be dismissed by a majority of the petitioners if they own at least 60 percent of the area owned by all of the petitioners as described in the petition.
(b) The proceeding may be dismissed at any time before the proposed drainage project is established after payment of the cost of the proceeding. If the costs cannot be collected, each and all petitioners are liable for unpaid assessments. The drainage authority shall determine and assess the cost of the proceeding against the persons liable. After the proceeding is dismissed any other action on the proposed drainage project must begin with a new petition.
Subd. 2. Delay. The drainage authority may delay drainage proceedings and drainage project construction under this chapter if a majority of the petitioners petition for a delay and the drainage authority holds a hearing on the petition. The delay may be for a period determined by the drainage authority. The drainage authority shall determine the cost of the proceedings up to the time the proceedings are delayed and when the costs are to be paid. The costs may include interest on the costs due.
History: 1990 c 391 art 5 s 33
Copyright ©2024 LegalFix. All rights reserved. LegalFix is not a law firm, is not licensed to practice law, and does not provide legal advice, services, or representation. The information on this website is an overview of the legal plans you can purchase—or that may be provided by your employer as an employee benefit or by your credit union or other membership group as a membership benefit.
LegalFix provides its members with easy access to affordable legal services through a network of independent law firms. LegalFix, its corporate entity, and its officers, directors, employees, agents, and contractors do not provide legal advice, services, or representation—directly or indirectly.
The articles and information on the site are not legal advice and should not be relied upon—they are for information purposes only. You should become a LegalFix member to get legal services from one of our network law firms.
You should not disclose confidential or potentially incriminating information to LegalFix—you should only communicate such information to your network law firm.
The benefits and legal services described in the LegalFix legal plans are not always available in all states or with all plans. See the legal plan Benefit Overview and the more comprehensive legal plan contract during checkout for coverage details in your state.
Use of this website, the purchase of legal plans, and access to the LegalFix networks of law firms are subject to the LegalFix Terms of Service and Privacy Policy.